8.962. Public works contract defined — certain contract clauses against public policy, exceptions. — 1. As used in this section, the term "public works contract" means a contract of the state, county, city and other political subdivisions of the state, except the Missouri transportation department, for the construction, alteration, repair, or maintenance of any building, structure, highway, bridge, viaduct, pipeline, public works, or any other works dealing with construction, which shall include, but need not be limited to, moving, demolition, or excavation performed in conjunction with such work.
2. Any clause in a public works contract that purports to waive, release, or extinguish the rights of a contractor to recover costs or damages, or obtain an equitable adjustment, for delays in performing such contract, if such delay is caused in whole, or in part, by acts or omissions within the control of the contracting public entity or persons acting on behalf thereof, is against public policy and is void and unenforceable.
3. Subsection 2 of this section is not intended to render void any contract provision of a public works contract that:
(1) Precludes a contractor from recovering that portion of delay costs caused by the acts or omissions of the contractor or its agents;
(2) Requires notice of any delay by the party responsible for such delay;
(3) Provides for reasonable liquidated damages; or
(4) Provides for arbitration or any other procedure designed to settle contract disputes.
---- end of effective 28 Aug 2022 ----
|
|||
Click here for the Reorganization Act of 1974 - or - Concurrent Resolutions Having Force & Effect of Law | |||
In accordance with Section 3.090, the language of statutory sections enacted during a legislative session are updated and available on this website on the effective date of such enacted statutory section. |
![]() |
||
|
Recent Sections | Editorials | May Be Cited As | Tables & Forms | Multiple Enact |
Repeal & Transfer | Definitions | End Report | ||
|
||||
Site changes | Pictures | Kontakt |
Legislative Research | Oversight | MOLIS | |||
Library | MO WebMasters |
Errors / suggestions - [email protected] |
![]() |
©Missouri Legislature, all rights reserved. | |||||||
![]() |
![]() |
![]() |
![]() |